Welcome to BluePrint Build-Con. These Terms and Conditions ("Terms") constitute a legally binding agreement between you ("Client", "User", "Partner", or "You") and BluePrint Build-Con regarding your access to and use of our website, mobile interfaces, architectural blueprinting, site consultation, turnkey civil construction services, and referral partner programs.
By browsing our platform, booking a site inspection, submitting a construction inquiry, enrolling in the referral program, or executing a construction work order, you acknowledge that you have read, understood, and agreed to be bound by these Terms and our Privacy Policy.
1. Acceptance & Scope of Terms
These Terms govern all interactions with BluePrint Build-Con, including digital interfaces, offline consultations, architectural blueprint deliveries, structural calculations, site supervision, material procurement, and general turnkey building execution.
If you are entering into these Terms on behalf of a company, partnership, society, or other legal entity, you represent and warrant that you possess the full legal authority to bind such entity to these obligations.
2. Services, Blueprints & Turnkey Contracts
BluePrint Build-Con provides comprehensive architectural and civil construction services, including but not limited to:
- Architectural Design & 3D Elevation: Conceptual floor layouts, 3D modeling, Vastu-compliant blueprints, and MEP (Mechanical, Electrical, Plumbing) designs.
- Structural Engineering: Soil testing coordination, RCC frame design, load-bearing calculations, and seismic resistance planning as per Bureau of Indian Standards (IS codes).
- Turnkey Residential & Commercial Construction: Complete project execution from excavation and foundation to brickwork, plastering, premium flooring, painting, and handover.
- Project Management & Quality Audits: Digital stage tracking, quality checks (slump test, cube test, steel grade checks), and scheduled milestone reviews.
3. Estimates, Quotations & Price Validity
Preliminary estimates provided on the website or via initial WhatsApp discussions are ballpark projections based on standard square-foot packages. Final binding contracts are based on an exhaustive Bill of Quantities (BOQ) prepared after comprehensive soil inspection and architectural finalization.
Quote Validity: Formal written quotations remain valid for thirty (30) calendar days from issuance due to market fluctuations in core commodity prices (cement, TMT steel, and sand).
Price Escalation Clause: Unless an explicit fixed-price turnkey agreement is executed, material price escalations beyond ±10% in government indices may be adjusted as defined in the master work order.
4. Stage-Wise Milestone Payments
To protect client funds and maintain total financial transparency, our turnkey contracts operate strictly on milestone-based payments:
Work will not proceed to the subsequent milestone unless the preceding stage payment has been verified and settled.
5. Client Responsibilities & Site Clearances
The client is responsible for providing:
- Clear Land Title & Demarcation: Unencumbered ownership, peaceful site possession, and marked boundary stones.
- Statutory Approvals & Sanctions: Building permission from municipal authorities (PMC, PCMC, BBMP, or local Gram Panchayat), with architectural liaison support from our team.
- Water & Power Supply: Continuous construction-grade water and electrical connection at site for labor, mixing, and curing operations.
- Safe Access: Unobstructed vehicular access for transit mixers, RMC trucks, and material haulers.
6. Referral Program & Partner Commission
Under the BluePrint Build-Con Refer & Earn Program, channel partners, existing clients, and individuals may earn referral cash rewards ranging from ₹10,000 to ₹1,00,000+ per successful project:
- Lawful Consent: Referrer warrants that they have informed the prospective client and obtained their consent prior to submitting their contact number and project scope.
- Eligibility: Referral rewards apply strictly to new, verified inquiries that culminate in signed turnkey or architectural contracts. Self-referrals or existing pipeline leads are excluded.
- Payout Timeline: Cash commission is disbursed via UPI/Bank Transfer within 7–14 business days after the referred client completes contract signing and the first milestone advance.
- Taxation: Referral payouts are subject to applicable TDS (Tax Deducted at Source) under Indian Income Tax regulations.
7. Material Standards & Structural Warranty
We build to rigorous Indian Standard (IS) benchmarks using top-tier materials:
Warranty excludes unauthorized structural alterations made by the client after handover, unauthorized third-party drilling, natural disasters (earthquake exceeding design limit, flooding), or intentional misuse.
8. Delays & Force Majeure
BluePrint Build-Con is committed to on-time handover as committed in the master schedule. However, timelines will be reasonably extended without liability in cases of Force Majeure:
- Acts of God, unseasonal severe weather, floods, earthquakes, pandemics, or government-imposed construction halts (e.g. NGT pollution bans).
- Delays in client milestone payments or delayed approvals of finishes, tiles, or sanitary selections.
- Local neighborhood disputes, court stay orders, or utility disconnections outside the Company's control.
9. Scope Modifications & Change Orders
Any modifications to approved blueprints, additions of built-up area, wall relocations, or specification upgrades requested after contract signing will be documented through a formal Variation / Change Order detailing revised costs and timeline adjustments before implementation.
10. Cancellation, Suspension & Refunds
In the event of project cancellation by the client prior to ground excavation, booking fees are refunded minus actual expenses incurred (site surveys, soil testing fees, structural calculations, and 3D architectural design hours).
Once physical ground excavation or RCC work has commenced, funds corresponding to completed work and procured on-site materials are non-refundable. A joint measurement audit will be performed to settle accounts.
11. Intellectual Property & Blueprints
All 2D floor plans, 3D renderings, structural blueprints, design layouts, and technical documentation produced by BluePrint Build-Con remain the intellectual property of the Company. The client is granted an exclusive, non-transferable license to construct the specific project on the designated plot. Resale or commercial reuse of plans on other sites is prohibited.
12. Limitation of Liability
To the maximum extent permitted by applicable Indian law, the Company's total aggregate liability arising out of or related to any project engagement, whether in contract, tort, or warranty, shall not exceed the actual management and execution fees paid by the client under the specific work order in dispute.
13. Governing Law & Dispute Resolution
These Terms shall be governed by and construed in accordance with the laws of the Republic of India.
Arbitration: Any dispute, controversy, or claim arising out of or relating to this contract shall be settled amicably through mutual discussion within thirty (30) days. Failing such resolution, the dispute shall be referred to arbitration under the Arbitration and Conciliation Act, 1996, before a sole arbitrator mutually appointed by both parties.
Jurisdiction: Subject to arbitration, the courts having jurisdiction in Pune, Maharashtra shall have exclusive jurisdiction over any legal proceedings.